工事代金の未払いに関する契約書の雛形を以下に示します。日本法に基づく契約書の雛形と、英語契約書の雛形を両方提供します。これらの雛形は一般的なものであり、具体的な契約に応じて調整が必要です。
日本法に基づく工事契約書雛形
工事契約書
本契約は、以下の通り、工事の実施に関する条件を定めるものである。
第1条(契約の目的)
本契約は、契約者(以下「甲」という。)と受注者(以下「乙」という。)との間で、甲が乙に対して発注する工事(以下「本工事」という。)の内容、条件等を定めるものである。
第2条(工事の内容)
- 本工事の内容は、別紙「工事内容明細書」に記載の通りとする。
- 本工事は、甲が指定する場所で実施するものとし、工事の完了予定日は[完了予定日]とする。
第3条(契約金額)
- 本工事の契約金額は、[金額]円(消費税別途)とする。
- 甲は、本工事の完了後、乙に対し、契約金額の支払いを行うものとする。
第4条(支払い条件)
- 甲は、乙からの請求書受領後[支払い期日]以内に、指定口座に振り込む方法により、工事代金を支払うものとする。
- 支払いが遅延した場合、甲は年率[遅延利率]%の遅延損害金を支払うものとする。
第5条(未払いの対応)
- 甲が支払い義務を履行しない場合、乙は支払い請求書を発行するものとする。
- 甲が請求書受領後[猶予期間]以内に支払いを行わない場合、乙は法的手続きを取ることができるものとする。
第6条(契約の解除)
- 乙は、甲が本契約に定める支払い義務を履行しない場合、契約の解除を請求することができるものとする。
- 契約解除の際、乙は既に履行した工事の対価を請求することができる。
第7条(その他)
- 本契約に関する紛争は、[管轄裁判所]の裁判所で解決するものとする。
- 本契約の変更または追加は、書面による合意が必要とする。
甲:
(会社名)
(住所)
(代表者名)
乙:
(会社名)
(住所)
(代表者名)
英文契約書雛形
CONTRACT AGREEMENT
This Contract Agreement (the "Agreement") is made and entered into on [Date], by and between:
Contractor: [Contractor's Name], located at [Address] (hereinafter referred to as "Party A")
Subcontractor: [Subcontractor's Name], located at [Address] (hereinafter referred to as "Party B")
Article 1: Purpose of the Contract
This Agreement is for the purpose of defining the terms and conditions for the construction work to be performed by Party B for Party A.
Article 2: Scope of Work
- The scope of the work is as described in the attached "Scope of Work" document.
- The work will be performed at the location specified by Party A and is scheduled to be completed by [Completion Date].
Article 3: Contract Price
- The contract price for the work is [Amount] JPY (excluding tax).
- Party A shall make payment to Party B upon completion of the work.
Article 4: Payment Terms
- Party A shall make payment within [Payment Due Date] days of receiving an invoice from Party B, by transferring the amount to the designated account.
- In the event of delayed payment, Party A shall pay interest at the rate of [Late Interest Rate]% per annum.
Article 5: Non-Payment Remedies
- If Party A fails to fulfill its payment obligations, Party B shall issue a demand for payment.
- If Party A fails to make payment within [Grace Period] days after receiving the demand, Party B may take legal action.
Article 6: Termination of Contract
- Party B may request termination of the contract if Party A fails to fulfill its payment obligations.
- Upon termination, Party B may claim compensation for the work already performed.
Article 7: Miscellaneous
- Any disputes arising from this Agreement shall be resolved by the courts of [Jurisdiction].
- Any modifications or additions to this Agreement must be made in writing and agreed upon by both parties.
Party A:
(Company Name)
(Address)
(Representative's Name)
Party B:
(Company Name)
(Address)
(Representative's Name)